Zafer Taahhut Insaat v. United States

by
Zafer, an Ankara, Turkey, contractor, and the Army Corps of Engineers (USACE) entered into a firm-fixed-price contract to construct the MILCON Support Facility at the Bagram Air Force Field in Afghanistan. Zafer was responsible for delivering materials to the site, and assumed the risk “for all costs and resulting loss or profit.” After issuing notice to proceed, USACE recognized that it could not make the project site available immediately and increased the contract price and set a new completion date. In November 2011, Pakistan closed its border from the seaport city of Karachi along the land routes into Afghanistan in response to a combat incident with the U.S. and NATO. The route remained closed for 219 days, Zafer notified USACE that the closure would greatly impact its delivery of materials and requested direction on how to proceed. USACE replied that the closure was “purely the act of Pakistan governmental authorities,” that the U.S. government was “not responsible” and denied further compensation. Zafer subsequently, repeatedly, asked for payment for additional costs. In 2013, Zafer submitted an unsuccessful request for an equitable adjustment. The contracting officer found no evidence supporting a constructive change claim. The Claims Court granted USACE summary judgment. The Federal Circuit affirmed. Zafer failed to designate specific facts to establish a constructive change claim based on either a constructive acceleration theory or on a government fault theory. View "Zafer Taahhut Insaat v. United States" on Justia Law