K-Con, Inc. v. Secretary of the Army

K-Con and the Army entered into two contracts for pre-engineered metal buildings. K-Con claims that the Army subsequently delayed issuance of a notice to proceed for two years, resulting in $116,336.56 in increases in costs and labor. According to K-Con, this delay was due solely to the government’s decision to add to each contract the performance and payment bonds set forth in Federal Acquisition Regulation (FAR) 52.228-15. The Armed Services Board of Contract Appeals held that bonding requirements were included in the contracts by operation of law when they were awarded, pursuant to the Christian doctrine. The Federal Circuit affirmed. The two contracts are construction contracts and, under the Christian doctrine, the standard bond requirements in construction contracts were incorporated into K-Con’s contracts by operation of law. If the contracts had been issued using the standard construction contract form, there would have been no issue, but these contracts issued using the standard commercial items contract form. There were, however, many indications that the contracts were for construction, not commercial items. The statement of work included many construction-related tasks, including developing and submitting construction plans, obtaining construction permits, and cleaning up construction areas. The statement of work also required compliance with FAR regulations relevant only to construction contracts. View "K-Con, Inc. v. Secretary of the Army" on Justia Law