Justia Government Contracts Opinion Summaries

Carnell, a "minority-owned" corporation, filed suit against the Housing Authority and Blaine based on claims of race discrimination, retaliation, and breach of contract. The court held that a corporation can acquire a racial identity and establish standing to seek a remedy for alleged race discrimination under Title VI of the Civil Rights Act of 1964, 42 U.S.C. 2000d, but that the district court properly dismissed one of the defendants from liability on plaintiff's race discrimination claims; the district court abused its discretion in permitting the use of particular impeachment evidence, which should have been excluded as unfairly prejudicial under Federal Rule of Evidence 403; and the district court properly reduced certain damages awarded to plaintiff on its contract claims, but decided that the strict notice requirements of the Virginia Public Procurement Act, Virginia Code 2.2-4300 through 4377, required the court to narrow further the scope of recoverable contract damages. Accordingly, the court affirmed in part, vacated in part, and remanded for further proceedings. View "Carnell Construction Corp. v. Danville RHA" on Justia Law

In 2002, the Navy awarded Metcalf a contract to design and build 212 housing units in Hawaii by October, 2006, for $50 million. Problems arose involving soil conditions. The request for proposals stated that the “soil reconnaissance report” was “for preliminary information only” and required that the contractor conduct independent soil investigation, incorporating 48 C.F.R. 52.236-2, concerning site conditions that differ materially from those disclosed. Discussions delayed construction for a year. Metcalf implemented its preferred changes by over-excavating and using non-expansive fill, without a contract modification. The Navy denied that there was any material difference between pre-bid and post-award soil assessments, but approved some modifications. Metcalf was about 200 days behind schedule and began using “post-tension” concrete, which was more expensive but avoided the additional time and cost of over-excavation. The Navy amended the contract to approve use of post-tension concrete slabs. Metcalf claims additional delays resulting from the presence of more of a chemical contaminant than was expected. With respect to contamination, the Navy granted a 286-day extension and reimbursed $1,493,103. The Navy accepted the buildings in March, 2007. Metcalf alleged that its final cost was $76 million. The government paid less than $50 million. The Claims Court ruled in favor of the government, under the Contract Disputes Act, 41 U.S.C. 7104. The Federal Circuit vacated, holding that the court misconstrued what Metcalf needed to show to prove that the government breached its duty of good faith and fair dealing and misinterpreted certain contractual provisions.View "Metcalf Const. Co., LLC v. United States" on Justia Law

In 2001 KBR agreed to provide the Army with logistics support services during Operation Iraqi Freedom. Individual task orders required KBR to install, operate and maintain dining services near Mosul, Iraq on a cost-plus-award-fee basis. KBR selected ABC, a subcontractor, to build a prefabricated metal dining facility and to provide dining services for a camp population of 2,573. In June 2004, the Army ordered KBR to stop construction of the metal facility and begin construction of a reinforced concrete facility for an estimated 2,573 to 6,200+ persons. Instead of requesting bids for the new work, KBR kept ABC as the subcontractor due to the urgency of the request. ABC submitted a new proposal with a total monthly cost about triple the monthly cost initially quoted. ABC attributed the increased costs to additional labor and equipment to serve a larger population and to a drastic increase in the cost of labor and a severe shortage of staff willing to work in Iraq. Due to a calculation error, it was determined that ABC’s proposal was reasonable. KBR’s management reviewed and approved a change order, embodying ABC’s proposal. In 2005 the subcontract ended and title to the dining facility passed to the Army. In 2007, the Defense Contract Auditing Agency suspended payment of certain costs paid by KBR to ABC pursuant to the change order. KBR prepared a new price justification for the concrete dining facility and ultimately filed suit, seeking recovery of the $12,529,504 in costs disapproved for reimbursement. The Claims Court awarded $6,779,762. The Federal Circuit affirmed.View "Kellogg Brown & Root Servs. v. United States" on Justia Law

The Town of Kearny hired Brandt-Kuybida Architects to design and plan the construction of a new public safety facility. Construction began in 1994. The general contractor, Belcor Construction, signed a "Certificate of Substantial Completion" in late 1995. Approximately ten days later, the architects signed the same Certificate. The Certificate defined the date of substantial completion in language similar to that of the construction contract. The signatories to the Certificate, however, left the "date of issuance" and the "date of completion" of the project blank. In Spring1996, the Town's Construction Official issued the first Temporary Certificate of Occupancy (TCO), limited to the police section of the building. Structural defects in the facility surfaced shortly after the Kearny Police Department took occupancy, including leaks, buckled tiles and cracks in the walls. By 2007, ceilings in the facility had fallen and pipes had separated and pulled, all of which were attributed to uneven settlement. The Town never issued a final certificate of occupancy and on February 8, 2007, had the building vacated. Belcor initiated arbitration proceedings against the Town because the Town withheld final payment under the contract. Belcor and the Town resolved their dispute by Stipulation of Settlement. Both the Stipulation of Settlement and the related Town of Kearny Resolution identified the date of substantial completion of the facility as February 1, 1996. The issues before the Supreme Court were: (1) when could a building be considered substantially complete for purposes of calculating the ten-year period of the statute of repose; and (2) whether the Comparative Negligence Act and the Joint Tortfeasors Contribution Law authorized the allocation of fault to defendants who obtained dismissals pursuant to the statute of repose. The Supreme Court concluded after review that (1) the ten year period of the statute of repose started when the first Temporary Certificate of Occupancy was issued for the facility; and (2) when the claims against a defendant are dismissed on statute of repose grounds, fault may be apportioned to the dismissed defendant under the Comparative Negligence Act and the Joint Tortfeasors Contribution Law.View "Townof Kearny v. Brandt" on Justia Law

This appeal stemmed from a protracted contract dispute arising out of the construction of Meridian’s new City Hall. The City brought suit against the project’s construction manager, Petra, Inc., alleging that Petra breached the parties’ agreement in a number of ways. The City further claimed that Petra was not entitled to any additional fees for its work. Petra counterclaimed, seeking an equitable adjustment of its construction manager fee. After trial, the district court entered its findings of fact and conclusions of law, ruling against the City on all but one of its claims and awarding Petra an additional fee for its services. The court awarded Petra $595,896.17 in costs and $1,275,416.50 in attorney fees, but stayed enforcement of the judgment pending appeal. The City appealed. Finding no error in the district court's judgment in favor of Petra, the Supreme Court affirmed. View "City of Meridian v. PETRA Inc." on Justia Law

The Phenix City Board of Education ("the Board") sought mandamus relief from the Russell Circuit Court's denial of the Board's motion to dismiss or, in the alternative, for a summary judgment on claims brought against it by The Lisle Company, Inc. ("Lisle"). Because the Board is immune from suit pursuant to § 14, Ala. Const. 1901, the Supreme Court granted the Board's petition and issued the writ. View "Lisle Company, Inc. v. Phenix City Board of Education" on Justia Law

Patrick Engineering signed a 2007 contract with the City of Naperville for work on a stormwater management system. Some work was done and some payments were made, but the parties fell into a dispute over “additional services.” Patrick terminated the agreement and sued Naperville, seeking $436,392. The agreement provided that if Naperville made a verbal request for additional services, the engineers were required to confirm that request in writing and were not obligated to perform the changes until authorized in writing. This procedure was not followed; equitable estoppel became the crux of the case. The trial court dismissed. The appellate court reversed. The city did not appeal with respect to claims of quantum meruit and under the Illinois Local Government Prompt Payment Act, which remain pending in the trial court. The supreme court reversed with respect to other claims and reinstated the dismissals. While equitable estoppel may apply against municipalities in extraordinary and compelling circumstances, Illinois courts have never held that apparent authority may be applied against municipalities. To recover in equitable estoppel, plaintiff must allege specific facts showing that municipal officials possessed actual, rather than apparent, authority on which plaintiff reasonably relied.View "Patrick Eng'g v. City of Naperville" on Justia Law

In 2004-2005, Costa & Son Construction performed site work for the general contractor (Braitt) on such a project in Bridgewater. After Braitt terminated the relationship Costa sued, alleging breach of contract and violations of G.L. c. 93A. Costa sought to recover damages under a payment bond obtained by Brait from Arch Insurance, G.L. c. 149, 29. Brait asserted similar counterclaims against Costa. Arch argued that Costa had relinquished any right to claim against the bond pursuant to a provision of his subcontract with Brait. The trial court granted Brait and Arch directed verdict with respect to claims under the bond. A jury returned a verdict for Costa, against Brait. The Massachusetts Supreme Court vacated the directed verdict. A subcontractor on a public construction project for which a payment bond has been obtained by the general contractor pursuant to G.L. c. 149, 29, may not by private agreement forgo its right to pursue payment under the bond. The court also vacated the portion of the amended judgment granting consequential damages to Costa; consequential damages were precluded by the contract. View "Costa v. Brait Builders Corp." on Justia Law

This case arose out of a contractual dispute between the city and its contractor and sub-contractor concerning the design and construction of an underground parking garage. At issue was whether the city's petition for a writ of certiorari to the court of appeals to decide whether that court erred when it determined the trial judge did not err when, having been presented with a motion to recuse him, he denied the motion rather than referred it to another judge. The court held that, since the affidavits at issue raised a reasonable question about the trial judge's impartiality that required the assignment of the motion to recuse to another judge, the court of appeals erred when it affirmed the trial judge's denial of the motion to recuse for failure to meet the requirement of USCR 23.5. Accordingly, the court reversed and remanded.View "Mayor & Alderman of the City of Savannah v. Batson-Cook Co., et al." on Justia Law

Roxco, Ltd., was hired as the general contractor for several public-construction projects for the State of Mississippi, including four building projects at the University of Mississippi, Jackson State University, and Alcorn State University. State law requires that a certain percentage of the cost of construction be retained to ensure completion. However, Mississippi Code Section 31-5-15 (Rev. 2010) allows the contractor to access that retainage by depositing with the State other acceptable security. Pursuant to Section 31-5-15, Roxco substituted securities valued at $1,055,000, deposited in a safekeeping account at Trustmark National Bank. Upon being notified of Roxco's default, the State instructed Trustmark to transfer the funds from the treasury bills into the state treasury account. By letter, Roxco directed Trustmark not to transfer the funds from the treasury bills to the State's account. Notwithstanding Roxco's letter, Trustmark deposited the funds into the State's account. Roxco filed suit against Trustmark for breach of contract and conversion. Trustmark argued that Section 31-5-15 permitted the release of the funds in the safekeeping account. A jury found in favor of Roxco and awarded $3,720,000 in damages. Aggrieved, Trustmark appealed. Finding that the trial court should have granted the motion for judgment notwithstanding the verdict, the Supreme Court reversed and remanded for further proceedings.View "Trustmark National Bank v. Roxco Ltd." on Justia Law