Justia Government Contracts Opinion Summaries

Articles Posted in Intellectual Property
by
This case involves a dispute between two tribally owned businesses, AQuate II, LLC and Kituwah Services, LLC, both of which compete for federal contracts under the Small Business Administration’s 8(a) Business Development Program. AQuate alleges that Kituwah and its employee, Jessica Myers, stole trade secrets related to a government contract that AQuate had won in the past. AQuate claims that Myers, a former employee, breached her employment agreements and violated both the Defend Trade Secrets Act of 2016 and the Alabama Trade Secrets Act. Kituwah, however, argues that it is shielded by tribal sovereign immunity, while Myers contends that her employment contract mandates that any claims against her can only be brought in a designated tribal court.The United States District Court for the Northern District of Alabama dismissed the case, finding that Kituwah had not waived sovereign immunity for the trade secrets claims and that the claims against Myers should be resolved in the Alabama-Quassarte Tribal Town court, as stipulated in her employment contract. AQuate appealed the decision, arguing that the tribal court did not exist.The United States Court of Appeals for the Eleventh Circuit reversed the district court’s decision. The appellate court found that Kituwah had waived sovereign immunity for claims related to the federal contracting program and could be sued. Regarding Myers, the court determined that the district court failed to consider whether the clause naming the allegedly nonexistent tribal court as the appropriate forum was valid and enforceable. The case was remanded for further consideration. View "Aquate II, LLC v. Myers" on Justia Law

by
In 2010, the Army granted Authentic a nonexclusive license to manufacture and sell clothing bearing the Army’s trademarks. The agreement required the Army’s advance written approval of any products and marketing materials bearing the Army’s trademarks and included exculpatory clauses that exempted the Army from liability for exercising its discretion to deny approval. In 2011-2014, Authentic submitted nearly 500 requests for approval; the Army disapproved 41 submissions. During that time, Authentic received several formal notices of material breach for claimed failures to timely submit royalty reports and pay royalties. Authentic eventually paid its royalties through 2013. Authentic’s counsel indicated that Authentic would not pay outstanding royalties for 2014.Authentic's ensuing breach of contract suit cited the Army’s denial of the right to exploit the goodwill associated with the Army’s trademarks, refusal to permit Authentic to advertise its contribution to Army recreation programs, delay of approval for a financing agreement, denial of approval for advertising, and breach of the implied duty of good faith and fair dealing by not approving the sale of certain garments. The Federal Circuit affirmed summary judgment in favor of the government. The license agreement stated in no uncertain terms that the Army had “sole and absolute discretion” regarding approval of Authentic’s proposed products and marketing materials; the exercise of that broad approval discretion is not inconsistent with principles of trademark law. View "Authentic Apparel Geoup, LLC v. United States" on Justia Law

by
In 2013, the Naval Facilities Engineering Command installed copyrighted graphics-rendering software created by German company Bitmanagement onto all computers in the Navy-Marine Corps Intranet. No express contract or license agreement authorized the Navy’s actions. In 2016, Bitmanagement filed suit, alleging copyright infringement, 28 U.S.C. 1498(b). The Claims Court found that, while Bitmanagement had established a prima facie case of copyright infringement, the Navy was not liable because it was authorized to make copies by an implied license, arising from the Navy’s purchase of individual licenses to test the software and various agreements between the Navy and the vendor.The Federal Circuit vacated and remanded for the calculation of damages. The Claims Court ended its analysis prematurely by failing to consider whether the Navy complied with the terms of the implied license, which can readily be understood from the parties’ entire course of dealings. The implied license was conditioned on the Navy using a license-tracking software, Flexera, to “FlexWrap” the program and monitor the number of simultaneous users. The Navy failed to effectively FlexWrap the copies it made; Flexera tracking did not occur as contemplated by the implied license. That failure to comply creates liability for infringement. View "Bitmanagement Software GMBH v. United States" on Justia Law

by
The Navy began a program to design and build littoral combat ships (LCS) and issued a request for proposals. During the initial phase of the LCS procurement, FastShip met with and discussed a potential hull design with government contractors subject to non-disclosure and confidentiality agreements. FastShip was not awarded a contract. FastShip filed an unsuccessful administrative claim, alleging patent infringement. The Claims Court found that the FastShip patents were valid and directly infringed by the government. The Federal Circuit affirmed.The Claims Court awarded FastShip attorney’s fees and expenses ($6,178,288.29); 28 U.S.C. 1498(a), which provides for a fee award to smaller entities that have prevailed on infringement claims, unless the government can show that its position was “substantially justified.” The court concluded that the government’s pre-litigation conduct and litigation positions were not “as a whole” substantially justified. It unreasonable for a government contractor to gather information from FastShip but not to include it as part of the team that was awarded the contract and the Navy took an exceedingly long time to act on FastShip’s administrative claim and did not provide sufficient analysis in denying the claim. The court found the government’s litigation positions unreasonable, including its arguments with respect to one document and its reliance on the testimony of its expert to prove obviousness despite his “extraordinary skill.” The Federal Circuit vacated. Reliance on this pre-litigation conduct in the fee analysis was an error. View "FastShip, LLC v. United States" on Justia Law

by
Hitkansut owns the patent, entitled “Methods and Apparatus for Stress Relief Using Multiple Energy Sources.” While the application that later issued as that patent was pending, Hitkansut entered into a non-disclosure agreement with Oak Ridge National Laboratory (ORNL) and provided ORNL with a copy of the then-unpublished patent application. ORNL staff prepared research reports, received funding, authored publications, and received awards for research, based upon unauthorized use of the patent. Hitkansut sued ORNL, alleging infringement under 28 U.S.C. 1498. The Claims Court determined that certain claims of the patent were invalid but that other claims were valid and infringed. Although Hitkansut originally sought a royalty between $4.5-$5.6 million, based on a percentage of the research funding obtained by ORNL, the Claims Court awarded $200,000, plus interest, as the hypothetically negotiated cost of an up-front licensing fee. The Federal Circuit affirmed.Hitkansut then sought attorneys’ fees and expenses under 28 U.S.C. 1498(a). The Claims Court awarded $4,387,889.54.The Federal Circuit affirmed. Section 1498(a) provides for the award of attorneys’ fees under certain conditions, unless “the court finds that the position of the United States was substantially justified.” The “position of the United States” in this statutory provision refers to positions taken during litigation and does not encompass pre-litigation conduct by government actors, but the examples of conduct cited by the Claims Court demonstrate that the position of the United States was not substantially justified even under this narrow definition View "Hitkansut LLC v. United States" on Justia Law

by
The Army Corps of Engineers awarded Ikhana a contract to build a Pentagon facility by October 12, 2015. Ikhana procured required performance and payments bonds from GCNA, which required Ikhana to execute a general indemnity agreement, including a provision that assigned GCNA all rights under the contract if Ikhana defaulted or if GCNA made a payment on any bond. Each time Ikhana discovered a new worksite problem, it had to halt work until the Corps issued a unilateral contract change, causing significant delays and cost overruns. One modification required a power outage at the Pentagon, but the Corps never scheduled the outage. By mid-October 2015, construction stopped; Ikhana submitted claims seeking additional compensation and an extension of the deadline. Ikhana’s sub-contractors filed claims against GCNA’s bond. The Corps terminated Ikhana and made a claim on the bond. Ikhana appealed the termination and its claims to the Armed Services Board of Contract Appeals. GCNA and the Corps negotiated for GCNA to tender a completion contractor. GCNA invoked the indemnity agreement and entered into a settlement with the Corps then sought a declaratory judgment that the agreement authorized it to settle Ikhana’s dispute with the Corps and dismiss the Board appeal. The district court stayed GCNA’s action pending resolution of Ikhana’s Board appeal. The Federal Circuit affirmed the denial of GCNA’s motion to intervene and withdraw Ikhana’s Board appeal. GCNA lacked standing. A party seeking to supplant the plaintiff must be able to show that it could have initiated the complaint on its own. GCNA’s settlement agreement with the Corps, even if it constitutes a takeover agreement, does not entitle GCNA to assert claims that arose before the settlement. View "Guarantee Co. of North America USA v. Ikhana, LLC" on Justia Law

by
Fuqua, a computational linguist, was hired by SVOX in 2009 to help market linguistic products. A few months later, SVOX approached Fuqua with a new employment contract that contained an inventions assignment clause that required Fuqua to disclose and assign to SVOX intellectual property that he made, conceived, or developed in the past and required assignment of his rights to patents, copyrights, trademarks, trade secrets, and royalties to SVOX. Fuqua believed that the disclosure required by the new agreement would violate state and federal laws and refused to sign the contract. SVOX terminated Fuqua’s employment. Fuqua filed a complaint with the Office of Inspector General of the Department of Defense (OIG), alleging violation of the American Recovery and Reinvestment Act of 2009, which prohibits reprisals for disclosures of wrongdoing relating to covered funds under the act. The OIG found that SVOX did not receive Recovery Act funds and declined to investigate further. The district court dismissed, finding that SVOX did not receive covered funds. The Seventh Circuit affirmed. View "Fuqua v. SVOX USA, Inc." on Justia Law

by
USM builds military boats. Working with VT Halter, USM designed a special-operations craft with a hull made out of composite materials for use in competing for the Navy's “MK V Special Operations Craft and Transporter System Contract.” With its 1993 bid, VT Halter submitted drawings stamped with a “Limited Rights Legend” to invoke Defense Federal Acquisition Regulations Supplement Section 252.227-7013(a)(15), which limits governmental use and disclosure of certain information. VT Halter won the contracts and delivered 24 Mark V special-operations craft. In 2004, the Navy awarded University of Maine a research grant to improve the ride and handling of the Mark V and provided detailed design drawings of the Mark V to contractors, stamped with the DFARS Limited Rights Legend, but did not obtain VT Halter’s consent for disclosure. The Navy awarded Maine Marine a contract to design and construct a prototype Mark V.1. USM sued under the Federal Tort Claims Act, 28 U.S.C. 1346(b), alleging misappropriation of trade secrets. The district court awarded damages, but the Fifth Circuit held that the matter lay exclusively within the jurisdiction of the Court of Federal Claims under the Tucker Act, 28 U.S.C. 1491(a)(1). The Fifth Circuit vacated the judgment and ordered transfer. The Federal Circuit affirmed. View "U.S. Marine, Inc. v. United States" on Justia Law

by
Gaylord created “The Column,” sculptures representing soldiers that are the centerpiece of the Korean War Veterans' Memorial on the National Mall. The Postal Service issued a stamp commemorating the 50th anniversary of the armistice, with a photograph of The Column, licensed from a photographer. USPS issued roughly 86.8 million of the stamps, sold retail goods with the image, and licensed the image to retailers, without seeking Gaylord's permission. In 2006, Gaylord sued under 28 U.S.C. 1498(b) for copyright infringement. The Federal Circuit held that Gaylord owned the copyright and that USPS was liable for infringement, but remanded for determination of damages. The Court of Federal Claims rejected a claim for a 10 percent royalty on about $30.2 million in revenue allegedly generated by the infringing use, as well as a claim for prejudgment interest, finding that neither 28 U.S.C. 1498(b), which waives sovereign immunity for copyright infringement, nor the copyright infringement statute, 17 U.S.C. 504, authorizes a royalty-based award for copyright infringement and that the proper measure of damages was the reasonable value of a license, between $1,500 and $5,000. The Federal Circuit vacated and remanded for determination of market value of the infringing use and award of prejudgment interest. View "Gaylord v. United States" on Justia Law