Justia Government Contracts Opinion Summaries

The Army Corps of Engineers retained JMR as general contractor for construction of a dental clinic at the Presidio of Monterey. JMR entered into separate electrical and plumbing subcontracts with EAR. SureTec issued separate bonds guaranteeing EAR’s performance. While the project was ongoing, JMR communicated with EAR about alleged delays, deficient and late submittals, and improper work, and retained certain funds otherwise due EAR. After the project was completed, JMR sued EAR and SureTec for breach of contract and for foreclosure of the bonds. EAR filed a cross-complaint to recover retention funds withheld under the subcontracts. JMR was awarded $315,631, which included an offset for retention funds. The court held that JMR was entitled to attorney fees for its successful defense of the cross-complaint; awarded JMR $90,644.07 in expert witness fees, concluding that JMR’s recovery exceeded its $375,000 pretrial settlement offers. The court of appeal affirmed the judgment but reversed the award of expert fees. The court upheld utilization of the Eichleay method to calculate extended home office overhead damages; use of the modified total cost method of calculating JMR’s disruption and delay damages; and finding SureTec liable under the bonds because formal notice of default was not a condition precedent to recovery. View "JMR Constr. Corp. v. Envtl Assessment & Remediation Mgmt., Inc." on Justia Law

In 2008, Javidan shadowed Shahab, who was involved with fraudulent home-health agencies. Javidan, Shahab, and two others purchased Acure Home Care. Javidan managed Acure, signing Medicare applications and maintaining payroll. She had sole signature authority on Acure’s bank account and, was solely responsible for Medicare billing. Javidan illegally recruited patients by paying “kickbacks” to corrupt physicians and by using “marketers” to recruit patients by offering cash or prescription medications in exchange for Medicare numbers and signatures on blank Medicare forms. Javidan hired Meda as a physical therapist. Meda signed revisit notes for patients that he did not visit. He told Javidan which patients were not homebound and which demanded money for their Medicare information. The government charged both with health care fraud conspiracy (18 U.S.C. 1347) and conspiracy to receive kickbacks (18 U.S.C. 371). At trial, Javidan testified that she did not participate in and was generally unaware of Acure’s fraudulent business practices. Meda called no witnesses. Javidan and Meda were sentenced to terms of 65 and 46 months of imprisonment, respectively. The Sixth Circuit affirmed, rejecting Meda’s claims that his conviction violated the Double Jeopardy Clause and that he was subjected to prosecutorial vindictiveness for refusing to plead guilty and requesting a jury trial in prior case and Javidan’s claims of improper evidentiary rulings and sentence calculation errors. View "United States v. Javidan" on Justia Law

The California Department of Transportation (CalTrans) and Papich Construction Company, Inc. appealed a trial court’s issuance of a writ of mandate to vacate the award of a public works contract to Papich. DeSilva Gates Construction submitted the second-lowest bid (the first bidder was disqualified for a non-responsive bid), and included the names and description of work by all subcontractors slated to perform work exceeding one-half of one percent of the bid amount. DeSilva later sent a letter to CalTrans noting DeSilva had inadvertently supplied CalTrans with additional information on the subcontractor list "above and beyond what was required." DeSilva explained it had not listed "All Steel Fence" as a subcontractor in its bid because the value of the bid items it would perform was less than one-half of one percent of the bid and the information for All Steel Fence (submitted within 24 hours of the bid) was additional information that was not required. Papich challenged DeSilva’s bid as having changed the subcontractor list. CalTrans rejected DeSilva’s bid as nonresponsive. DeSilva protested CalTrans’s determination that its bid was nonresponsive and protested Papich’s bid. The trial court granted the writ on grounds CalTrans erroneously rejected DeSilva's bid, and erred by awarding the contract to Papich despite Papich’s failure to comply with a material requirement of the information for bids. On appeal, CalTrans and Papich argued DeSilva’s bid was nonresponsive. Appellants also argued CalTrans had discretion to waive Papich’s mistake in failing to acknowledge the addendum to the information for bids. After review, the Court of Appeal concluded the trial court did not err. DeSilva’s disclosure of a subcontractor performing work amounting to only one-tenth of one percent of the total value of the contract was not required by the Public Contract Code or CalTrans’s information for bids. The additional information was accurate, albeit unnecessary, and did not render DeSilva’s bid nonresponsive. By contrast, CalTrans initially declared Papich’s bid to be nonresponsive and then waived Papich’s mistake and determined the bid to be responsive. The Court concluded CalTrans abused its discretion by awarding Papich the contract. Accordingly, the Court affirmed the trial court’s issuance of the writ of mandate. View "DeSilva Gates Construction, LP v. Dept. of Transportation" on Justia Law

Plaintiffs, Woodward employees, filed a qui tam action under the False Claims Act, alleging that Woodward falsely certified helicopter engine parts that it sold to the government. Plaintiffs had complained that the sensors at issue did not meet quality standards and had refused to work on the order. Following an investigation, a Defense Contract Management Agency Technical Specialist concluded that there was “nothing either incorrect or wrong with the procedures, assembly, or testing of the sensors.” The government continues to order, pay for, and use Woodward’s sensor The Seventh Circuit affirmed summary judgment in favor of Woodward, agreeing that even if Woodward made false statements to the government, no reasonable jury could find that it made the statements knowingly or that the statements were material. View "Marshall v. Woodward, Inc." on Justia Law

Plaintiff, a construction company, filed this suit after the Arkansas State Claims Commission (ASCC) denied a claim by Plaintiff related to a contract Plaintiff had entered into with the Arkansas State Highway Commission (ASHC) to complete a highway improvement project. Plaintiff named as defendants the ASCC, the ASHC, and the Arkansas State Highway and Transportation Department (ASHTD). In its complaint, Plaintiff challenged the constitutionality of the method by which the State resolves claims against it, asserting that the procedures violated the Due Process Clause. After a remand by the Supreme Court, the circuit court dismissed Plaintiff’s due process claim and equal protection claim as barred by sovereign immunity. On appeal, Plaintiff argued that the circuit court erred in dismissing its due process claim. The Supreme Court affirmed, holding that Plaintiff failed to demonstrate an unconstitutional act on the part of Defendants that would except its due process claim from the doctrine of sovereign immunity. View "Duit Constr. Co. v. Ark. State Claims Comm'n" on Justia Law

These interlocutory appeals were from a district court order that, inter alia, compelled a law firm (Mintz Levin) to produce documents relating to a fraud allegedly committed by David Gorski in his operation of Legion Construction, Inc. in order to qualify for and obtain government contracts. Gorski and Legion appealed the portion of the order that required attorney-client privileged documents connected with Mintz Levin’s representation of Legion to be produced under the crime-fraud exception. The government cross-appealed the portion of the district court decision to exclude communications between Gorski and his personal attorney from the production order. The First Circuit (1) dismissed Gorski’s appeal for want of appellate jurisdiction, holding that the Court did not have jurisdiction over Gorski’s appeal but did have jurisdiction over Legion’s appeal and the government’s cross-appeal; (2) affirmed the production order as to Mintz Levin, holding that a prima facie case for the crime-fraud exception had been made; and (3) vacated the district court’s decision to exclude Gorski’s communications with his personal attorney from the production order, holding that the district court employed incorrect legal reasoning with regard to these documents. View "United States v. Gorski" on Justia Law

Plaintiff filed a qui tam action under the False Claims Act (FCA), 31 U.S.C. 3729 et seq., and for defamation under Michigan law, alleging that WSU engaged in a fraudulent scheme to inflate the amount of funding that it received from the federal government for research grants and that he was fired in retaliation for complaining about the scheme to university officials and refusing to participate in it. The court concluded that the district court correctly held that WSU is an arm of the State of Michigan and therefore not a “person” subject to liability under the FCA; the district court was correct in dismissing plaintiff’s defamation claim as barred by the Eleventh Amendment; plaintiff failed to plead his conspiracy and “Reverse False Claim Act” claims with particularity under Fed. R. Civ. P. 9(b); plaintiff's argument that his retaliation claim under the FCA should not have been dismissed because, while WSU may not be a “person” under the FCA, WSU is an “employer” under the FCA that may still be sued for retaliation, is forfeited; and the district court properly denied plaintiff’s request to amend the complaint as futile. Accordingly, the court affirmed the judgment. View "Kreipke v. Wayne State Univ." on Justia Law

After the United States prevailed in a civil action brought pursuant to the False Claims Act (FCA), 31 U.S.C. 3729, based on certifications by MWI to the Bank to secure loans financing MWI's sale of water pumps to Nigeria, a jury awarded the government $7.5 million in damages. The damages were trebled to $22.5 million pursuant to the FCA. Because an FCA defendant is entitled to an offset from the trebled damages by any amount paid to compensate the government for the harm caused by the false claims, and the district court considered Nigeria’s repayment of the loan to be compensatory, MWI’s damages were reduced from $22.5 million to $0. The district court did impose civil penalties at the highest level. The government appealed and MWI cross-appealed. The court reversed the judgment because the government failed to establish that MWI knowingly made a false claim. Absent evidence that the Bank, or other government entity, had officially warned MWI away from its otherwise facially reasonable interpretation of an undefined and ambiguous term, the FCA’s objective knowledge standard, as the Supreme Court clarified while this litigation was pending in Safeco Insurance Co. of America v. Burr, did not permit a jury to find that MWI “knowingly” made a false claim. View "United States ex rel. Purcell v. MWI Corp." on Justia Law

Respondent was the low bidder on a government construction contract. The Purchasing Division of the Department of Administration and the Lottery Commission (collectively, the Agency), however, awarded the contract to Petitioner, the next low bidder, determining that Petitioner was the lowest qualified responsible bidder on the project. Petitioner filed suit to rescind the contract. The circuit court ordered the Agency to award the contract to Respondent, concluding that the determination to disqualify Respondent was not rational. The Supreme Court affirmed, holding that the Agency abused its discretion when it awarded the construction contract to Petitioner. View "Wiseman Constr. Co. v. Maynard C. Smith Constr. Co." on Justia Law

White Oak Corporation and the Department of Transportation entered into a contract for the reconstruction of a bridge and a portion of Interstate 95 in the City of Bridgeport. The project experienced significant delays such that the Department and White Oak reassigned the contract to another contractor for completion. White Oak subsequently filed a notice of claim and demand for arbitration seeking compensation for money wrongfully withheld by the Department, as liquidated damages, for delays in the project. An arbitration panel concluded that the liquidated damages clause in the parties’ contract was unenforceable, and therefore, White Oak was entitled to a return of nearly $5 million withheld by the Department. The trial court granted White Oak’s application to confirm the arbitration award. The Appellate Court reversed, concluding that the arbitration panel exceeded its authority in rendering an award on White Oak’s claim. The Supreme Court reversed, holding that the Appellate Court incorrectly determined that, in a prior action brought by the Department to enjoin the arbitration, the trial court limited the scope of the arbitrable issues in the present case to a claim of wrongful termination such that the arbitration panel lacked jurisdiction to decide White Oak’s liquidated damages claim. View "Dep’t of Transp. v. White Oak Corp." on Justia Law