Justia Government Contracts Opinion Summaries

The Federal Acquisition Regulation, 48 C.F.R. 9.407-4(b), governs the acquisition of supplies and services by all federal agencies. At issue was whether a federal agency may suspend two affiliates of an indicted government contractor for the duration of the legal proceedings against the indicted contractor under the Regulation. Because the suspension of an affiliate was included as part of the suspension of the indicted government contractor, the court concluded that legal proceedings initiated against the indicted government contractor tolled the 18-month time limit for the suspension of the affiliates. Accordingly, the court reversed the grant of summary judgment in favor of the affiliates and rendered a judgment in favor of defendants.View "Agility Defense & Gov't Svcs, et al. v. U.S. Dept. of Defense, et al." on Justia Law

The issue before the Supreme Court in this case centered on a contract dispute between the State of Vermont and Corizon Health, Inc., formerly known as Prison Health Services, Inc. (PHS). The State appealed a declaratory judgment ruling that PHS was not contractually obligated to defend the State and its employees against certain claims brought by the estate of an inmate who died while in the custody of the Department of Corrections.  Upon review of the contract in question, the Supreme Court reversed, concluding that PHS had a duty to defend.View "Vermont v. Prison Health Services, Inc." on Justia Law

Relators filed suit in district court asserting claims arising from a Direct Procurement Method (DPM) scheme. The DOD instituted the International Through Government Bill of Lading program to govern transoceanic moves, while relying on the DPM to contract for transport strictly on the European continent. These appeals and cross-appeals were taken from final judgments, entered in accordance with Rule 54(b), in two qui tam actions consolidated for litigation in district court. The court concluded that relator possessed standing to sue for civil penalties while bypassing the prospect of a damages award and, therefore, the court affirmed the district court's judgment in his favor; the court reversed and remanded to the extent that the district court denied relator discovery of any penalties; and the court vacated the district court's ruling in favor of the United States so that it could conduct further proceedings on what remained of the government's FCA claim and reentered judgment as appropriate.View "United States ex rel. Kurt Bunk v. Gosselin World Wide Moving" on Justia Law

After a hearing, the Department of Children and Families substantiated allegations that Plaintiff, an elementary school teacher, emotionally abused one of his students and recommended that Plaintiff’s name be placed on the Department’s central registry of child abuse and neglect. The trial court affirmed, ruling that the ultimate finding of the administrative hearing officer was supported by substantial evidence. The Appellate Court reversed and ordered the Department to remove Plaintiff’s name from the central registry. The Supreme Court reversed, holding that the Appellate Court (1) failed properly to credit the factual findings and legal conclusions of the administrative hearing officer; and (2) improperly concluded that the definition of “abused” found in Conn. Gen. Stat. 46b-120(3) was void for vagueness as applied to the facts of this case. View "Frank v. Dep’t of Children & Families" on Justia Law

American General Contractors, Inc. ("AGC"), appealed a judgment assessing liability and awarding damages and interest for the cost of delays in the construction of the Williams County Law Enforcement Center in Williston. C&C Plumbing and Heating, LLP ("C&C"), the successful bidder for the mechanical prime contract, filed suit when construction the center was delayed approximately two years after "substantial completion" was supposed to have happened. The district court concluded it was appropriate for the County and AGC to share responsibility for providing temporary shelter and heat on the project. The court apportioned 47 percent of the liability for the costs of the delay for the three and one-half months of active interference to the County and 53 percent to AGC, for the four months delay inherent to the industry. The court awarded C&C approximately $73,000 on its claim against the County. After offsetting amounts owed between the parties, the court awarded AGC approximately $424,000 on its claim against the County. The court awarded Davis Masonry approximately $96,000 from AGC for masonry work completed under its subcontract with AGC, and rejected AGC's claimed offsets to that amount. Davis had provided heat, cover and shelter for the project during cold weather and sought $649,000 from the County and AGC for that expense including prompt payment interest. Davis had settled with the County for $530,000, and the court ruled AGC was responsible for 53 percent of the remaining $119,000, or $63,070. AGC argues the district court erred in determining AGC was liable for any of the costs incurred from the delay under its contract with the County. Finding no reversible error, the Supreme Court affirmed the district court. View "C&C Plumbing and Heating, LLP v. Williams County" on Justia Law

Relator filed a qui tam action under the False Claims Act (FCA), 31 U.S.C. 3729 et seq., alleging that his former employer, NCED, along with other defendants, defrauded the government through various schemes in connection with contracts pursuant to the Javits-Wagner-O'Day Act, 41 U.S.C. 8501 et seq. After NCED and its former CEO settled, the district court dismissed relator's claims against the remaining defendants. The court held that the public-disclosure bar deprived the district court of jurisdiction over relator's claims against Defendants NISH, Green Bay, IPC, and Smurfit. With respect to these defendants, the district court properly determined that relator's proposed amendments to his first amended complaint were futile. The court held that relator's second amended complaint failed to adequately plead an FCA claim against Defendant Weyerhaeuser. Accordingly, the court affirmed the judgment of the district court. View "US ex rel. Ahumada v. NISH" on Justia Law

Bachner Company and Bowers Investment Company were unsuccessful bidders on a public contract proposal. They filed a claim for intentional interference with prospective economic opportunity against four individual procurement committee members. The superior court found that the bidders failed to present a genuine issue of material fact regarding the committee members' alleged bad faith conduct. The superior court then held that the committee members were protected by qualified immunity and that the lawsuit was barred by the exclusive remedy statute. The bidders thereafter appealed. Upon review, the Supreme Court concluded that the bidders indeed failed to present a genuine issue of material fact regarding the committee members' alleged bad faith. Furthermore, the exclusive remedy statute barred the bidders' suit. Accordingly, the Court affirmed the trial court's decision. View "Bachner Company, Inc. v. Weed" on Justia Law

MMS Construction & Paving, L.L.C. entered into a subcontract with Head, Inc. to pave asphalt runway shoulders at Altus Air Force Base in Oklahoma. The project was delayed and MMS, expressing concern that Head had not been making agreed payments, quit the job. MMS also complained that completing the job would be more expensive than it originally believed because certain requirements were being imposed that Head said would be waived. After MMS quit, Head finished the job, relying on other subcontractors. MMS sued Head on state-law claims of breach of contract, tortious breach of contract, quantum meruit, and misrepresentation, and brought a claim under the federal Miller Act on Head’s surety bond for the project. Head filed a counterclaim, alleging that MMS breached the contract. After a jury trial, MMS was awarded damages and attorney fees. Head filed a motion for judgment as a matter of law or for a new trial, both of which the district court denied. Head appealed, arguing: (1) the evidence at trial was insufficient to show that Head breached the contract; (2) if there was a breach, it was not material; (3) an Oklahoma statute limited MMS’s breach-of-contract damages to the amount unpaid plus interest; (4) the evidence was not sufficient to establish MMS’s alleged lost-profits damages for breach of contract; (5) MMS did not present sufficient evidence to prove misrepresentation or any damages from misrepresentation, MMS waived the misrepresentation claim, and the award of misrepresentation damages duplicated the award of damages for breach of contract; and (6) MMS was not entitled to attorney fees from Head because the Miller Act does not allow recovery of those fees. Upon careful consideration of the district court record, the Tenth Circuit reversed damages award based on the misrepresentation claim because the jury’s award was not supported by any evidence at trial. On all other issues, the Court affirmed. View "MMS Construction & Paving v. Head, Inc., et al" on Justia Law

In 2011, the Agency of Transportation advertised for bids to reconstruct a half-mile section of North Main Street in downtown Barre. Luck Brothers submitted the low bid and was awarded the contract for the project, which it started in the summer of 2011. In June 2012, Luck Brothers submitted a claim to the Agency seeking approximately $855,000 in additional compensation beyond the bid amount based on alleged differing site conditions from those assumed in the contract. One year later, Luck Brothers submitted a supplemental claim, making the total claim approximately $1.1 million. Less than three months after submitting its $855,000 claim, Luck Brothers filed a complaint against the Agency in superior court seeking, among other things, declaratory relief and compensatory damages. Specifically, the complaint alleged breach of contract, negligent misrepresentation, and breach of an implied warranty on the part of the Agency, and sought penalties under the Prompt Pay Act. Luck Brothers appealed the superior court’s decision to grant the Agency’s motion to dismiss Luck Brothers’ lawsuit on grounds that the company failed to exhaust its administrative remedies before pursuing a remedy in the superior court. Upon review, the Supreme Court affirmed the superior court’s decision, but clarified the standard of review in appeals to the Vermont Transportation Board from Agency determinations under the claims process for construction contracts. View "Luck Brothers v. Agency of Transportation" on Justia Law

The Village of Bement, Piatt County, has a five-year contract, under which E.R.H. Enterprises operates and maintains the Village’s potable water facility and parts of its water delivery infrastructure. The Department of Labor issued a subpoena to E.R.H.’s attorney seeing employment records as part of an investigation under the Prevailing Wage Act, 820 ILCS 130/0.01. E.R.H. asserted that it was exempt from the Act as a public utility. The trial court ruled in favor of the Department and ordered E.R.H. to provide the requested documents, noting that the company was not regulated by the Illinois Commerce Commission. The appellate court reversed. The Illinois Supreme Court reversed the appellate court, finding that E.R.H. is simply an outside contractor. View "People v. IL Dep't of Labor" on Justia Law